R21-036 (Award Rescinded) 1 RESOLUTION NO. R21-036
2
3 A RESOLUTION OF THE CITY OF BOYNTON BEACH, FLORIDA,
4 APPROVE AWARD OF BID NO. 002-2511-21/RW, HARVEY E.
5 OYER JR. PARK MARINA BOAT RAMP IMPROVEMENT
6 PROJECT,AND AUTHORIZE THE CITY MANAGER TO SIGN AN
7 AGREEMENT WITH TO ISSUE A PURCHASE ORDER TO ANZCO,
8 INC. OF BOCA RATON, FL AS THE LOWEST RESPONSIVE,
9 RESPONSIBLE BIDDER IN THE AMOUNT OF $967.538.00 PLUS
10 CONTINGENCY AMOUNT OF $232,462.00 FOR A TOTAL
11 ESTIMATED AMOUNT OF $1,200,000.00; AND PROVIDING AN
12 EFFECTWE DATE.
13
14 WHEREAS, on March 12, 2021, Procurement Services opened three (3) bids in
15 response to the Bid for"Harvey E.Oyer Jr Park Marina Boat Ramp Improvement Project";
16 and
17 WHEREAS, after reviewing the three(3)bids submitted,Purchasing verified that
18 all three bids were responsive to the bid requirements, possess the requisite licenses and
19 have the capacity to obtain the requisite insurance and payment or performance bonds;
20 and
21 WHEREAS, Public Works Department,Engineering/Facility staff recommended
22 the project be awarded to the lowest responsive and responsible bidder Anzco, Inc; and
23 WHEREAS, the City Commission of the City of Boynton Beach upon
24 recommendation of staff, deems it to be in the best interest of the citizens and residents to
25 approve the Award Bid No.002-2511-21/RW,Harvey E.Oyer Jr.Park Marina Boat Ramp
26 Improvement Project, and authorize the City Manager to sign an agreement with to issue
27 a Purchase Order to Anzco, Inc. of Boca Raton, FL as the lowest responsive,responsible
28 bidder in the amount of$967.538.00 plus contingency amount of$232,462.00 for a total
29 estimated amount of$1,200,000.00.
30 NOW, THEREFORE, BE IT RESOLVED BY THE CITY COMMISSION
31 OF THE CITY OF BOYNTON BEACH,FLORIDA,THAT:
32 Section 1. The foregoing"Whereas" clauses are hereby ratified and confirmed
S:\CA\RESO\Agreements\Award of Bid for Oyer Park Marina Boat Ramp-Reso.docx
1 as being true and correct and are hereby made a specific part of this Resolution upon
2 adoption.
3 Section 2. The City Commission of the City of Boynton Beach, Florida,
4 hereby approves the Award Bid No. 002-2511-21/RW, Harvey E. Oyer Jr. Park Marina
5 Boat Ramp Improvement Project, and authorizes the City Manager to sign an Agreement
6 with to issue a Purchase Order to Anzco,Inc. of Boca Raton,FL as the lowest responsive,
7 responsible bidder in the amount of$967.538.00 plus contingency amount of$232,462.00
8 for a total estimated amount of$1,200,000.00. A copy of the Agreement is attached
9 hereto and incorporated herein as Exhibit"A".
10 Section 3. That this Resolution shall become effective immediately.
11 PASSED AND ADOPTED this (Q day of April,2021.
12 CITY OF BOYNTON BEACH,FLORIDA
13 YES NO
14
15 Mayor—Steven B.Grant ✓
16
17 Vice-Mayor—Ty Penserga t/-
18 18
19 Commissioner—Justin Katz
20
21 Commissioner—Woodrow L.Hay
22
23 Commissioner—Christina L.Romelus
24
25 VOTE
26 ATTEST:
27
28 ' -n
29 //IL' rI_ Cali
30 Tammy Stanzio
31 Deputy City Cl rk
32
33 lbw 1
34 (Corporate Seal) •
np 1" t
I !to'?(1
•
•
/ M t
S:\CA\RESO\Agreements\Award of Bid for Oyer Park Iv1"a ina Boat Rantp-Reso.docx
1 '0(6(D i D
ry.rO N 6
HARVEY E. OYER JR. PARK MARINA BOAT RAMP IMPROVEMENT PROJECT
CONSTRUCTION CONTRACT
THIS AGREEMENT is entered into between the City of Boynton Beach, hereinafter referred to as"the City",
and Anzco. Inc., hereinafter referred to as"CONTRACTOR", in consideration of the mutual benefits,terms,
and conditions hereinafter specified.
PROJECT DESIGNATION.The Contractor is retained by the City to provide Harvey E. Oyer Jr. Park Marina
Boat Ramp Improvements.
NOW, THEREFORE, in consideration of these premises and the mutual conditions and covenants
contained herein, the parties agree as follows:
The CITY does award the contract to and does hire and employ the CONTRACTOR and the
CONTRACTOR does accept the award, predicated upon the bid of the CONTRACTOR, dated March 11,
2021, which is hereby incorporated by reference into this agreement, and the CONTRACTOR does agree
to furnish the necessary labor, tools, equipment, materials and supplies, etc., and to perform all the work
provided in the bid, contract documents, bond documents, plans and specifications for:
Bid Title: HARVEY E. OYER, JR. PARK MARINA BOAT RAMP
IMPROVEMENT PROJECT
Bid Number: 002-2511-21/RW
the City of Boynton Beach, Florida, all of which are incorporated herein by reference lump sum price as
specified in CONTRACTOR'S bid in the amount of:
NINE HUNDRED SIXTY-SEVEN THOUSAND AND FIVE HUNDRED THIRTY-EIGHT DOLLARS -$967,538.00
1.0 SCOPE OF SERVICES
1.1 CONTRACTOR further agrees to furnish all materials, supplies, machines, equipment,
tools, superintendents, labor, insurance, and other accessories and services necessary to
complete said project in accordance with the conditions and prices as stated in the contract,
General Conditions for Construction, and Supplementary Conditions for Construction,
plans which include all maps, plats, blueprints, and other drawings and printed or written
explanatory matter thereof as contained in the bid, contract documents and specifications
for the project.
1.2 All the work and labor performed under this contract shall be performed, and all of the
material furnished shall be, in strict conformity with said plans and specifications, and
CONTRACTOR accepts and consents to the conditions contained in said plans and
specifications and expressly agrees to comply with every requirement and stipulation
therein contained to be performed by the party contracting to do said work.
1.3 The CONTRACTOR further agrees to furnish all tools, equipment, materials and supplies
and to do all the work above mentioned in a first-class, substantial and workmanlike
manner, and in conformity with the detail for said work on file in the office of the City
Engineer of the City and strictly in accordance with the specifications, general stipulations
and plans which are hereby referred to and made a part of this contract, as well as to the
satisfaction of the City Commission and City Engineer of the said City, and in strict
obedience with the directions which may be given by the City Manager or his authorized
representative, at and for the prices herein plainly set forth.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-1
1.4 Upon receipt of written notification from the CITY,to correct any defective or faulty work or
materials which may appear within one(1)year after completion of the contract and receipt
of final payment. CONTRACTOR shall make the necessary corrections within ten(10)days
of receipt of the written notice.
1.5 To comply with the provisions of Section 255.05, Florida Statutes, if applicable.
1.6 To pay promptly, before final settlement, any and all claims or liens incurred in and about
this work. Furnish release of liens forms from all subcontractors and suppliers of materials.
Forms to be supplied by CITY.
1.7 The CONTRACTOR shall remove and clean up all rubbish, debris, excess material,
temporary structures, tools and equipment from streets, alleys, parkways and adjacent
property that may have been used or worked on by the CONTRACTOR in connection with
the project promptly as such section or portion is completed and ready for use, leaving the
same in a neat and presentable condition.
Payment of monthly or partial estimates may be withheld until this has been done to the
satisfaction of the City Engineer. Final acceptance and payment for the entire project will
not be made until the site is satisfactory to the CITY.
1.8 The CONTRACTOR shall at all times observe and comply with the provisions of the
charter, ordinances, codes and regulations of the City of Boynton Beach, Florida.
1.9 Upon completion of the work, the City Engineer shall satisfy himself, by examination and
test, that the work has been fully completed in accordance with the plans, specifications
and contract documents. When the City Engineer is so satisfied, he shall recommend
acceptance thereof to the City Manager,who shall, if he agrees with such recommendation,
present the final payment application to City Commission for review and vote to formally
accept the project. The right of general supervision of the CITY as hereinafter provided
under"authority of the Engineer"shall not make the CONTRACTOR an agent or employee
of the CITY, but the CONTRACTOR, shall at all times, and in all respects have the rights
and liabilities of an independent contractor.
1.10 After the cleaning up of the work, premises, streets, alleys, or other areas of structure in
anyway connected with the performance of the contract, the work as a whole shall be
inspected by the City Engineer, and any workmanship or material found not meeting the
requirements of the specifications shall be removed by or at the expense of the
CONTRACTOR and good and satisfactory workmanship or material substituted therefore.
All settlement, defects or damage upon any part of the work shall be remedied and made
good by the CONTRACTOR.
1.11 The CONTRACTOR will be held responsible for the care, protection and condition of all
work until final completion and acceptance thereof, and will be required to make good at
his own cost any damage or injury occurring from any cause.
2.0 TIME FOR PERFORMANCE
2.1 Work under this Agreement shall commence upon the giving of written notice by the City
to the Contractor to proceed. Contractor shall perform all services and provide all work
product required pursuant to this Agreement.
3.0 CONTRACT TIME
Contractor must commence work on a date to be specified in a written "Notice to Proceed" of the
CITY and to be fully complete 180 calendar days for substantial completion and Final Completion
shall be within 30 consecutive calendar days thereafter.
3.1 Upon failure of Contractor to obtain Substantial Completion within the deadline stated, plus
approved time extensions, Contractor shall pay to City the sum of $1,000.00 for each
calendar day after the deadline for Substantial Completion, plus any approved time
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-2
extensions, until Substantial Completion is obtained. Atter Substantial Completion, should
Contractor fall to complete the remalrttng woi k within the deadline stated In Paragraph 3.1,
plus approved time extensions thereof, Contractor shall pay to City the sum of$1,000 for
each calendar day after the deadline for Final Completion, plus any approved extensions,
until Final Completion is obtained. These amounts are not penalties but are liquidated
damages to City for its inability to obtain full beneficial occupancy of the Project. Liquidated
damages are hereby fixed and agreed upon between the Parties, recognizing the
impossibility of precisely ascertaining the amount of damages that will be sustained by City
as a consequence of such delay, and both Parties desiring to obviate any question of
dispute concerning the amount of said damages and the cost and effect of the failure of
Contractor to complete this contract on time.
3.2 The CITY shall have the right to deduct said liquidated damages from any amount due, or
that may become due the CONTRACTOR, or to collect such liquidated damages from the
CONTRACTOR or his Surety.
3.3 CONTRACTOR shall, as soon as practicable after signature of contract, confirm with City
Engineer in writing, the names of subcontractors as originally proposed for principal parts
of work, and for such others as City Engineer may direct. Contractor shall not employ and
that City Engineer may, within a reasonable time, object to as incompetent or as unfit.
4.0 PROTECTION OF EXISTING FACILITIES
4.1 The CONTRACTOR warrants that prices include the protection and continuous use of all
existing sewers, conduits, drains, pipes, buildings, walks, bridges, guard rails and other
construction encountered, and the prompt repairing of any damage done to them during
the progress of the work, or from insufficient support thereafter; also all the filling,
backfilling, tamping, ramming, puddling and consolidating; the removal and disposal of all
rubbish and surplus material; also all pumping bailing draining or unwatering of all
excavations, incidental to the execution of the work; also the furnishing of all necessary
labor,tools,equipment, materials and supplies,etc.and the performance of the whole work
mentioned in the detailed plans and specifications necessary to give a finished result, and
including all expense incurred in or in consequence of the suspension or discontinuance
of the said work specified and a faithful compliance with each and every one of the
requirements of the contract and for the maintenance of the entire work and construction
in good condition and repair until final acceptance.
4.2 The CONTRACTOR shall assume full responsibility and expense for the protection of all
public and private property, structures, water mains, sewers, utilities, etc., both above and
below ground, at or near the site or sites of the work being performed under the contract,
or which are in any manner affected by the prosecution of the work or the transportation of
men and materials in connection therewith. The CONTRACTOR shall give reasonable
written notice in advance to the department of the CITY having charge of any property or
utilities owned by the CITY and to other CITY or CITYs of public or private property or
utilities when they shall be affected by the work to be performed under the contract, and
shall make all necessary arrangements with such department,departments,CITY or CITYs
for the removal and replacement or protection of such property or utilities.
5.0 INDEMNIFICATION
5.1 The CONTRACTOR shall indemnify and save harmless and defend the CITY, its agents,
servants, and employees from and against any claim, demand, or cause of action of
whatsoever kind or nature arising out of error,omission or negligent act of CONTRACTOR,
its agents, servants, or employees in the performance of services under this Agreement.
5.2 CONTRACTOR shall indemnify and save harmless and defend CITY, its agents, servants
and employees from against any kind and all causes, claims, demands, actions, losses,
liabilities, settlements,judgments, damages, costs, expenses, and fees (including without
limitation reasonable attorney's and appellate attorney's fees)of whatsoever kind or nature
for damages to persons or property caused in whole or in part by any act, omission, or
default of the CITY, its agents, servants or employees arising from this contract or its
performance. The CONTRACTOR and the CITY hereby agree and covenant that the
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-3
CONTRACTOR has incorporated in this original bid, which constitutes the contract sum
payable by the CITY to the CONTRACTOR, specific addltIonal consideration sufficient to
support this obligation of indemnification provided for in this paragraph. It is the CITY'S and
CONTRACTOR'S full intention that this provision shall be enforceable and said provision
shall be in compliance with Florida Statute 725.06.
5.3 The execution of this Agreement by the CONTRACTOR shall obligate CONTRACTOR to
comply with the foregoing indemnification provision, as well as the insurance provisions
which are set forth herein. However, the indemnification provision, and the insurance
provision contained in this Contract are not interdependent of each other, each one is
separate and distinct from the other.
5.4 The obligation of the CONTRACTOR to indemnify the CITY is not subject to any offset,
limitation or defense as a result of any insurance proceeds available to either the CITY or
the CONTRACTOR.
6.0 PAYMENT BY CITY
6.1 The CITY agrees to pay the CONTRACTOR in current funds for the performance of the
contract, subject to additions and deductions as provided in the specifications.
6.2 PROSECUTION OF WORK
The work shall be prosecuted at such time or in or on such part or parts of the project which
such forces of workmen, materials and equipment as may be ordered by the Architect in
writing, to complete the project as outlined in the drawings, specifications, Contract and
schedules,including such detailed drawings as may be furnished by the Architect from time
to time during the prosecution of the work in explanation of said drawings. If at any time
the materials and appliances to be used appear to the Architect as insufficient or improper
for securing the quality of work required, or the required rate of progress, he may order the
Contractor to increase his efficiency or to improve the character of his work. The Contractor
shall conform to such an order. The failure of the Architect to demand any increase of such
efficiency or any improvement shall not release the Contractor from his obligation to secure
the quality of work or the rate of progress necessary to complete the work within the limits
imposed by the Contract.
a. The Contractor shall perform the work and take such precautions as he may deem
necessary to complete the project so all work will be in first-class and acceptable
conditions within the Contract time according to schedule.
b. If the Contractor desires to carry on work at night or outside the regular hours, he
shall submit application to the CITY, but he shall allow ample time to enable
satisfactory arrangements to be made for inspecting the work in progress. The
CITY could grant permission unless local regulations prohibit such work. If granted
permission,he shall comply with all regulations and legal requirements. Contractor
shall be responsible to pay for all inspection services outside of regular hours at a
rate of$100/hr.
6.3 WORKMANSHIP, MATERIAL AND WORKMEN
a. Unless otherwise stated in the detailed specifications, all workmanship, materials
and articles incorporated in the work covered by this Contract shall be of the most
suitable grade of their respective kinds for the purpose and acceptable to the
Architect. The Architect shall decide the question of quality where the expression
"or equal" is used in the specifications following reference to a specific
manufacturer of equipment or materials. When and to the extent required by the
specifications or by the Architect, the Contractor shall furnish the Architect for
review, full information concerning the materials or articles or methods of work
which he contemplates incorporating the work. Samples of materials shall be
submitted for review when requested. Machinery, materials, articles installed or
used, or unusual methods of work used without such review shall be at the risk of
subsequent rejection.
b. The CITY may require the Contractor to remove from the work such employees as
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-4
the(311Y deems incompetent, careless, insubordinate, or otherwise objectionable,
or whose continued employment on the work Is deemed to be contrary to the CITY'
interest.
6.4 DELAYS AND EXTENSION OF TIME
a. If the Contractor is delayed at any time in the progress of the work by any act or
neglect of the CITY or his employees, or by any other Contractor employed by the
CITY,or by changes ordered in the work,or by strikes,fire,lockouts, unusual delay
in transportation, unavoidable casualties or by delay authorized by the CITY
pending arbitration, or by any cause which the CITY shall decide to justify the
delay, then the time of completion may be reasonably extended by the CITY.
b. No extension shall be made for delay unless notice of a claim is made by the
Contractor in writing to the Architect within seven days of the event or incident
causing the delay.
c. If no schedule or agreement stating the dates upon which drawings shall be
furnished is made, then no claim for delay shall be allowed on account of failure to
furnish drawings until two weeks after demand in writing for such drawings and not
then unless such claim is reasonable and otherwise provided by "Notice" as
defined in the General Condition for Construction.
d. In the event of any delay in the project caused by any act or omission of the City,
its agents, or employees, the sole remedy available to Contractor shall be by
extension of the time allocated to complete the project. No monetary damages
shall be claimed or awarded to Contractor in association with any delay in the
project caused by any act or omission of the City, its agents or employees.
For the purpose of this section the phrase "the City, its agents and employees" shall include but
shall not be limited to the Architect, Project Supervisor, and consulting Architects.
This article does not exclude the recovery of damages by the City for delay caused by Contractor
under other provisions in the Contract Documents
7.0 CHANGES IN THE WORK
7.1 The CITY, without invalidating the Contract, may order extra work or make changes by
altering, adding to or deducting from the work, the Contract sum being adjusted
accordingly. All such work shall be executed under the conditions of the original Contract.
Any claim for extension of time caused thereby shall be made in writing at the time such
change is ordered.
7.2 All change orders and adjustments shall be in writing and approved by the City Manager
or City Commission if required, otherwise, no claim for extras will be allowed.
7.3 The General Contractor and all of his subcontractors shall be apprised of,and familiar with,
the following conditions and procedures governing extra work under the Contract:
a. Any change order has to be recommended by the City Manager and officially
approved by the City Commission before any steps are taken to implement the
change order.
b. Should the CONTRACTOR or any of his subcontractors commence with the work
without making a claim in writing for unforeseen extra work he encounters, it will
be construed as an acceptance and agreement by him that any such work is
required under the contract and no future claim for extras will be considered or
allowed by the CITY.
c. No claim for extra work will be allowed unless and until authority for same by written
Change Order has been obtained from the City Manager or the City Commission
of Boynton Beach, if necessary, which authorization will be signed by the Mayor.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-5
d. Changes in the work directed in writing by the CITY'S Representative under the
following procedures stTaIl become a part of the Contract by a written Change
Order.
e. Information regarding changes in the work involving claims to the CITY for
additional work, credits, and/or adjustments under the contract shall be promptly
transmitted in writing by the General CONTRACTOR to the CITY'S Representative
with full explanations and justifications for his consideration in preparing a Change
Order to the Contract.
7.4 The value of any change ordered under the Contract for extra work and/or any reductions
in work required, shall be determined under one or more of the following procedures before
a written Change Order is issued:
a. By such applicable unit prices, if any, as are set forth in the Contract except in
those cases where increases in quantities exceed fifteen (15) percent of the
original bid quantity and the total dollar change of that bid item is significant in the
opinion of the Engineer, the unit price shall be subject to review to determine if a
new unit price should be negotiated; or
b. If no such unit prices are set forth,then by a lump sum or other unit prices mutually
agreed upon by the CITY and the CONTRACTOR; or
c. By cost reimbursement, which is the actual cost for labor, direct overhead,
materials, supplies, equipment and other services necessary to complete the work
plus fifteen (15) percent to cover the cost of general overhead and profit. For all
labor and foreman in direct charge of the authorized operations, the
CONTRACTOR shall receive the current local rate of wages to be agreed upon in
writing before starting such work,for each hour said labor and foreman are actually
engaged thereon. An upper limit of total cost and of profit shall be agreed upon
and shall not be exceeded unless approved by the CITY.
a.) The CONTRACTOR shall submit sufficient cost and pricing data to enable the
Engineer to determine the necessity and reasonableness of costs and
amounts proposed and the allowability and eligibility of costs proposed.
b.) The CONTRACTOR shall have an accounting system which accounts for such
costs in accordance with generally accepted accounting principles. This
system shall provide for the identification, accumulation and segregation of
allowable and unallowable Change Order costs.
c.) Where it is indicated that the Contract is federally or State assisted, the
CONTRACTOR'S attention is directed to the applicable rules and regulations
relative to cost principles which must be used for the determination and
allowability of costs under grant.
d.) In no case shall fringe benefit costs on direct labor costs exceed forty (40)
percent of direct labor costs.
e.) In no case shall the CONTRACTOR and Subcontractors' general overhead
and profit in the aggregate exceed fifteen(15)percent of the total cost of direct
labor, fringe benefits, direct overhead, materials, supplies, equipment and
directly related services supplied by him. Among the items considered as
general overhead are bonds, insurance, incidental job burdens, supervision
and general office expenses.
f.) In no case shall the CONTRACTOR'S cost for administering subcontracts
exceed five (5) percent of the subcontractors' cost not including
subcontractors' profit.
g.) For special equipment and machinery such as power driven pumps, concrete
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-6
mixers, trucks, and tractors, or other equipment, required tor the economical
penbrmance of the authorized work, the CONTRACTOR shall receive
payment based on the agreed rental price for each item of equipment and the
actual time of its use on the work provided that the rental price shall not exceed
the current rates published by the Equipment Guide Book Company in the Blue
Book, "Rental Rates for Construction Equipment". Rate shall be daily, weekly
or monthly as appropriate.
h.) Records of extra work done shall be reviewed at the end of each day by the
CONTRACTOR and the Engineer. Such daily records shall clearly distinguish
between the work done under the contract and that done under the Change
Order. Duplicate copies of the accepted daily records shall be made, signed
by the CONTRACTOR and the Engineer and one copy retained by each.
7.5 Claim of payment for extra work shall be submitted by the CONTRACTOR upon certified
statement supported by receipted bills. Such statements shall be submitted for the current
contract payment for the month in which the work was done. No claim for extra work shall
be allowed unless that same was ordered, in writing, as aforesaid and the claim presented
at the time of the first estimate after the work is completed.
7.6 No Field Change Directive or Change Order shall be authorized by the Project Manager if
the Contractor has added language to the Field Change Directive or Change Order or to
any cover letter, e-mail, facsimile, or other written document which accompanies the Field
Change Directive or Change Order in which the contractor attempts to reserve any future
right or claim arising out of the work which is the subject of the Field Change Directive or
Change Order.
8.0 OWNERSHIP AND USE OF DOCUMENTS
8.1 All documents, drawings, specifications and other materials produced by the Contractor in
connection with the services rendered under this agreement shall be the property of the
City whether the project for which they are made is executed or not. The Contractor shall
be permitted to retain copies, including reproducible copies, of drawings and specifications
for information, reference and use in connection with Contractor's endeavors.
9.0 COMPLIANCE WITH LAWS
9.1 Contractor shall, in performing the services contemplated by this Agreement, faithfully
observe and comply with all federal,state of Florida and City of Boynton Beach,ordinances
and regulations that are applicable to the services to be rendered under this agreement.
10.0 INSURANCE
10.1 The Contractor shall secure and maintain in force throughout the duration of this contract
comprehensive general liability insurance with a minimum coverage of $1,000,000 per
occurrence and $1,000,000 aggregate for personal injury; and $1,000,000 per
occurrence/aggregate for property damage, and professional liability insurance in the
amount of $1,000,000 per occurrence to $2,000.000 aggregate with defense costs in
addition to limits.
10.2 Said general liability policy shall name the City of Boynton Beach as an additional named
insured and shall include a provision prohibiting cancellation of said policy except upon
thirty(30) days prior written notice to the City. Certificates of coverage as required by this
section shall be delivered to the City within fifteen(15)days of execution of this agreement.
11.0 INDEPENDENT CONTRACTOR
11.1 The Contractor and the City agree that the Contractor is an independent contractor with
respect to the services provided pursuant to this Agreement. Nothing in this Agreement
shall be considered to create the relationship of employer and employee between the
parties hereto. Neither Contractor nor any employee of Contractor shall be entitled to any
benefits accorded City employees by virtue of the services provided under this Agreement.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-7
The City shall not be responsible tor withholding or otherwise deducting tederal income tax
or Social Security or for contributing to the state industrial Insurance program, otherwise
assuming the duties of an employer with respect to Contractor, or any employee of
Contractor.
12.0 COVENANT AGAINST CONTINGENT FEES
12.1 The Contractor warrants that he has not employed or retained any company or person,
other than a bona fide employee working solely for the Contractor, to solicit or secure this
contract, and that he has not paid or agreed to pay any company or person, other than a
bona fide employee working solely for the Contractor any fee, commission, percentage,
brokerage fee, gifts, or any other consideration contingent upon or resulting from the
award or making of this contract.
For breach or violation of this warranty, the City shall have the right to annul this contract without
liability or, in its discretion to deduct from the contract price or consideration, or otherwise recover,
the full amount of such fee, commission, percentage, brokerage fee, gift, or contingent fee.
13.0 DISCRIMINATION PROHIBITED
13.1 The Contractor, with regard to the work performed by it under this agreement, will not
discriminate on the grounds of race, color, national origin, religion, creed, age, sex or the
presence of any physical or sensory handicap in the selection and retention of employees
or procurement of materials or supplies.
14.0 ASSIGNMENT
14.1 The Contractor shall not sublet or assign any of the services covered by this Agreement
without the express written consent of the City.
15.0 GUARANTEE AND WARRANTIES
15.1 All the work shall be guaranteed to remain in good condition for one year from date of
acceptance.
16.0 TERMINATION OF CONTRACT
16.1 If the work to be performed under the contract is assigned by the CONTRACTOR other
than provided for herein; if the CONTRACTOR should be adjudged as bankrupt; if a
general assignment of his assets be made for the benefit of his creditors; if a receiver
should be appointed for the CONTRACTOR or any of his property; if at any time the
Engineer shall certify in writing to the City Manager that the performance of the work under
the contract is being unnecessarily delayed or that the CONTRACTOR is willfully violating
any of the conditions, provisions, or covenants of the contract, plans or specifications, or
that he is executing the same in bad faith or otherwise not in accordance with the terms of
the contract; if the work be not fully completed within the time named for its completion or
within the time to which such completion date may be extended; or if other just causes
exist, the City Manager may serve ten (10) days' written notice upon the CONTRACTOR
of the intent to terminate the contract for the CITY and if the CONTRACTOR shall not, prior
to the effective date of termination set forth in such notice, take such measures as will, in
the judgment of the City Manager, ensure the satisfactory performance of the work, the
City Commission and the City Manager may declare the contract terminated on the
effective date specified in such notice,or any date subsequent thereto. In the event of such
termination, the City Manager shall notify the CONTRACTOR and Surety and the
CONTRACTOR shall immediately respect such notice and stop work and cease to have
any right to the possession of the ground and shall forfeit his contract. Upon such
termination, the City Manager shall provide the Surety with written notice of the CITY'S
action and the Surety shall within ten (10)days of receipt of said notice remedy the default
or the Surety shall as expeditiously as possible:
a. Complete the contract in accordance with its terms and conditions, or
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-8
b. Obtain a bid or bids tor completing the contract in accordance with its terms and
conditions, and upon determination by Surety and the CITY of the lowest
responsible bidder, make available as work progresses(even though there should
be a default or a succession of defaults under the contract or contracts or
completion arranged under this paragraph) sufficient funds to pay the cost of
completion less the balance of the contract price; but not exceeding, including
other costs and damages for which the Surety may liable hereunder, the amount
set forth in the first paragraph hereof. The term "balance of the contract price", as
used in this paragraph, shall mean the total amount payable by CITY to
CONTRACTOR under the contract and any amendments thereto, less the amount
properly paid by CITY to CONTRACTOR.
17.0 CONTRACT CONTROLS
17.1 The subject contract between the CITY and the CONTRACTOR shall supersede any and
all documents executed between the parties relative to the project. In the event of any
inconsistencies, the terms, provisions and conditions set forth in the subject contract shall
supersede all other documents and shall be controlling.
18.0 TIME OF ESSENCE
18.1 In as much as the provisions hereof, and of the plans and specifications herein, and of all
the other contract documents relating to the times of performance and completion of the
work are for the purpose of enabling the CITY to complete the construction of a public
improvement in accordance with a predetermined program, all such time limits are of the
essence of the contract.
19.0 REMEDY FOR DELAY
19.1 In the event of any delay in the project caused by any act or omission of the CITY, its
agents or employees, by the act or omission of any other party, or delay caused by weather
conditions or unavailability of materials, the sole remedy available to CONTRACTOR shall
be by extension of the time allocated to complete the project. No monetary damages shall
be claimed or awarded to CONTRACTOR in association with any delay in the project
caused by an act or omission of the CITY, its agents or employees.
19.2 Failure on the part of CONTRACTOR to timely process a request for an extension of time
to complete the work shall constitute a waiver by CONTRACTOR and CONTRACTOR shall
be held responsible for completing the work within the time allocated by this contract.
19.3 All requests for extension of time to complete the work shall be made in accordance with
the General Conditions for Construction.
19.4 For the purpose of this section the phrase "the CITY, its agents and employees" shall
include but shall not be limited to the Engineer, project manager and consulting Engineers.
20.0 NON-WAIVER
20.1 Waiver by the City of any provision of this Agreement or any time limitation provided for in
this Agreement shall not constitute a waiver of any other provision.
21.0 TERMINATION
21.1 The City reserves the right to terminate this Agreement at any time by giving thirty (30)
days written notice to the Contractor.
21.2 In the event of the death of a member, partner or officer of the Contractor, or any of its
supervisory personnel assigned to the project, the surviving members of the Contractor
hereby agree to complete the work under the terms of this Agreement, if requested to do
so by the City. This section shall not be a bar to renegotiations of this Agreement between
surviving members of the Contractor and the City, if the City so chooses.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-9
22.0 DISPUTES
22.1 Any disputes that arise between the parties with respect to the performance of this
Agreement, which cannot be resolved through negotiations, shall be submitted to a court
of competent jurisdiction in Palm Beach County, Florida. This Agreement shall be
construed under Florida Law.
23.0 NOTICES
Notices to the City of Boynton Beach shall be sent to the following address:
Lori LaVerriere, City Manager
City of Boynton Beach
P.O. Box 310
Boynton Beach, FL 33425-0310
Notices to Contractor shall be sent to the following address:
Anzco, Inc.
9671 Carousel Circle S
Boca Raton, FL 33434
Attn: John Zak
561-699-3602
24.0 INTEGRATED AGREEMENT
24.1 This agreement, together with attachments or addenda, represents the entire and
integrated agreement between the City and the Firm and supersedes all prior negotiations,
representations, or agreements written or oral. This agreement may be amended only by
written instrument signed by both City and Firm.
25.0 PUBLIC RECORDS
25.1 Sealed documents received by the City in response to an invitation are exempt from public
records disclosure until thirty (30) days after the opening of the Bid unless the City
announces intent to award sooner, in accordance with Florida Statutes 119.07.
The City is public agency subject to Chapter 119, Florida Statutes. The Contractor shall
comply with Florida's Public Records Law. Specifically, the Contractor shall:
A. Keep and maintain public records required by the CITY to perform the service;
B. Upon request from the CITY's custodian of public records, provide the CITY with a
copy of the requested records or allow the records to be inspected or copied within a
reasonable time at a cost that does not exceed the cost provided in chapter 119, Fla.
Stat. or as otherwise provided by law;
C. Ensure that public records that are exempt or that are confidential and exempt from
public record disclosure requirements are not disclosed except as authorized by law
for the duration of the contract term and, following completion of the contract,
Contractor shall destroy all copies of such confidential and exempt records remaining
in its possession once the Contractor transfers the records in its possession to the
CITY; and
D. Upon completion of the contract, Contractor shall transfer to the CITY, at no cost to the
CITY, all public records in Contractor's possession All records stored electronically
by Contractor must be provided to the CITY, upon request from the CITY's custodian
of public records, in a format that is compatible with the information technology systems
of the CITY.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-10
E. IF THE CONTRACTOR HAS QUESTIONS REGARDING
THE APPLICATION OF CHAPTER 119, FLORIDA
STATUES, TO THE CONTRACTOR'S DUTY TO PROVIDE
PUBLIC RECORDS RELATING TO THIS CONTRACT,
CONTACT THE CUSTODIAN OF PUBLIC RECORDS:
CRYSTAL GIBSON, CITY CLERK
100 E. OCEAN AVENUE
BOYNTON BEACH, FLORIDA, 33435
561-742-6061
GIBSONC@BBFL.US
26.0 E-VERIFY
26.1 Contractor certifies that it is aware of and complies with the requirements of Section
448.095, Florida Statues, as may be amended from time to time and briefly described
herein below.
1) Definitions for this Section:
"Contractor" means a person or entity that has entered or is attempting to enter into a
contract with a public employer to provide labor, supplies, or services to such employer in
exchange for salary,wages,or other remuneration. "Contractor"includes, but is not limited
to, a vendor or consultant.
"Subcontractor"means a person or entity that provides labor, supplies,or services to or for
a contractor or another subcontractor in exchange for salary,wages,or other remuneration.
"E-Verify system" means an Internet-based system operated by the United States
Department of Homeland Security that allows participating employers to electronically
verify the employment eligibility of newly hired employees.
2) Registration Requirement; Termination:
Pursuant to Section 448.095, Florida Statutes,effective January 1,2021,Contractors,shall
register with and use the E-verify system in order to verify the work authorization status of
all newly hired employees. Contractor shall register for and utilize the U.S. Department of
Homeland Security's E-Verify System to verify the employment eligibility of:
a) All persons employed by a Contractor to perform employment duties within
Florida during the term of the contract; and
b) All persons (including sub-vendors/sub-consultants/sub-contractors)
assigned by Contractor to perform work pursuant to the contract with the
City of Boynton Beach. The Contractor acknowledges and agrees that
registration and use of the U.S. Department of Homeland Security's E-
Verify System during the term of the contract is a condition of the contract
with the City of Boynton Beach; and
c) The Contractor shall comply with the provisions of Section 448.095, Fla.
Stat., "Employment Eligibility," as amended from time to time. This
includes, but is not limited to registration and utilization of the E-Verify
System to verify the work authorization status of all newly hired
employees. Contractor shall also require all subcontractors to provide an
affidavit attesting that the subcontractor does not employ, contract with,or
subcontract with, an unauthorized alien. The Contractor shall maintain a
copy of such affidavit for the duration of the contract. Failure to comply will
lead to termination of this Contract,or if a subcontractor knowingly violates
the statute, the subcontract must be terminated immediately. Any
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-11
challenge to termination under this provision must be tiled in the Circuit
Court no later than twenty(20)calendar days after the date of termination.
Termination of this Contract under this Section is not a breach of contract
and may not be considered as such. If this contract is terminated for a
violation of the statute by the Contractor, the Contractor may not be
awarded a public contract for a period of one (1) year after the date of
termination.
27.0 SCRUTINIZED COMPANIES-287.135 AND 215.473
27.1 By execution of this Agreement, Contractor certifies that Contractor is not participating in
a boycott of Israel. Contractor further certifies that Contractor is not on the Scrutinized
Companies that Boycott Israel list, not on the Scrutinized Companies with Activities in
Sudan List, and not on the Scrutinized Companies with Activities in the Iran Petroleum
Energy Sector List, or has Contractor been engaged in business operations in Syria.
Subject to limited exceptions provided in state law,the City will not contract for the provision
of goods or services with any scrutinized company referred to above. Submitting a false
certification shall be deemed a material breach of contract. The City shall provide notice,
in writing, to Contractor of the City's determination concerning the false certification.
Contractor shall have five (5) days from receipt of notice to refute the false certification
allegation. If such false certification is discovered during the active contract term,
Contractor shall have ninety (90) days following receipt of the notice to respond in writing
and demonstrate that the determination of false certification was made in error. If
Contractor does not demonstrate that the City's determination of false certification was
made in error then the City shall have the right to terminate the contract and seek civil
remedies pursuant to Section 287.135, Florida Statutes, as amended from time to time.
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-12
"This Agreement will take effect once signed by both parties. This Agreement may be signed by
the parties in counterparts which together shall constitute one and same agreement among the parties. A
facsimile signature shall constitute an original signature for all purpose."
IN WITNESS WHEREOF, the parties have hereto set their hands and seals on the day and year
set forth below their respective signatures.
IN WITNESS WHEREOF, the parties hereto have executed this Contract in multiple copies, each of which
shall be considered an original on the following dates:
DATED this day of , 20
CITY OF BOYNTON BEACH ANZCO, INC
Lori LaVerriere, City Manager (Signature), Authorized Official
Printed Name of Authorized Official
Attest/Authenticated:
Title
(Corporate Seal)
Crystal Gibson, City Clerk
Approved as to Form: Attest/Authenticated:
James A. Cherof, City Attorney Witness
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project C-13
GST Y O,
T~TON 6
PERFORMANCE BOND
KNOW ALL MEN BY THESE PRESENTS: that
(Insert name of Contractor)
as Principal,
(Address or legal title of Contractor)
hereinafter called Contractor, and
(Name and address of Surety)
as Surety, hereinafter called Surety, are held and firmly bound unto CITY OF BOYNTON BEACH,
P.O. BOX 310, BOYNTON BEACH, FLORIDA 33425-0310 as Obligee, hereinafter called Owner,
in the amount of Dollars
($ ), for payment whereof Contractor and Surety bind themselves, their
heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these
presents.
WHEREAS,
Contractor has by written agreement dated , 20 ,
entered into a contract with Owner for
in accordance with drawings and specifications prepared by
which contract is by reference made a part of hereof, and is hereinafter referred to as the Contract.
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED
AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PFB-1
NOW THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Contractor shall
promptly and faithfully perform such Contract, then this obligation shall be null and void; otherwise
it shall remain in full force and effect.
The Surety hereby waives notice of any alteration or extension of time made by the Owner.
Whenever Contractor shall be, and declared by Owner to be in default under the Contract, the
Owner having performed Owner's obligations thereunder, the Surety may promptly remedy the
default, or shall promptly:
1. Complete the Contract in accordance with its terms and conditions, or
2. Obtain a bid or bids for completing the Contract in accordance with its terms and conditions,
and upon determination by Surety of the most responsible bidder, or, if the Owner elects, upon
determination by the Owner and the Surety jointly of the most responsible bidder, arrange for
a contract between such bidder and Owner, and make available as work progresses (even
though there should be a default or a succession of defaults under the contract or contracts
of completion arranged under this paragraph) sufficient funds to pay the cost of completion
less the balance of the contract price; but not exceeding, including other costs and damages
for which the Surety may be liable hereunder, the amount set forth in the first paragraph
hereof. The term "balance of the contract price", as used in this paragraph, shall mean the
total amount payable by Owner to Contractor under the contract and any amendments thereto,
less the amount properly paid by Owner to Contractor.
Any suit under this bond must be instituted before the expiration of one (1)year from the date on
which final payment under the Contract falls due.
No right of action shall accrue on this bond to or for the use of any person or corporation other
than the Owner named herein or the heirs, executors, administrators or successors of the Owner.
This bond is issued in compliance with Section 255.05, Florida Statutes as may be amended. A
claimant, except a laborer, who is not in privity with the Contractor and who has not received
payment for its labor, materials, or supplies shall, within 45 days after beginning to furnish labor,
materials, or supplies for the prosecution of the work, furnish the Contractor with a notice that he
intends to look to the bond for protection. A claimant who is not in privity with the Contractor and
who has not received payment for its labor, materials, or supplies shall, within 90 days after
performance of the labor or after complete delivery of the materials or supplies, deliver to the
Contractor and to the Surety written notice of the performance of the labor or delivery of the
materials or supplies and the nonpayment. No action for the labor, materials, or supplies may be
instituted against the Contractor or the Surety unless both notices have been given. No action
shall be instituted against the Contractor or the Surety on the bond after one (1) year from the
performance of the labor or completion of delivery of the materials or supplies.
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED
AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PFB-2
Signed and sealed this day of , 2021.
Principal (Seal)
Witness
Title
Surety
Witness
Attorney-in-Fact
END OF PERFORMANCE BOND
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED
AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PFB-3
�,\SY Op
fJ 2
O - U
ETON 6
PAYMENT BOND
THIS BOND IS ISSUED SIMULTANEOUSLY WITH PERFORMANCE BOND IN FAVOR OF THE
OWNER CONDITIONED ON THE FULL AND FAITHFUL PERFORMANCE OF THE CONTRACT
KNOW ALL MEN BY THESE PRESENTS: that
(Insert name of Contractor)
as Principal,
(Address or legal title of contractor)
hereinafter called Principal, and
(Name and address of Surety)
as Surety, hereinafter called Surety, are held and firmly bound unto CITY OF BOYNTON BEACH,
P.O. BOX 310, BOYNTON BEACH, FLORIDA 33425-0310 as Obligee, hereinafter called Owner,
for the use and benefit of claimants as here below defined, in the amount of
Dollars ($ ), for payment whereof Principal and Surety bind themselves, their
heirs, executors, administrators, successors and assigns, jointly and severally, firmly by these
presents.
WHEREAS, Principal has by written agreement dated
2020, entered into a contract with Owner for
in
accordance with drawings and specifications prepared by
which contract is by reference made a part of hereof, and is hereinafter referred to as the Contract.
NOW THEREFORE, THE CONDITION OF THIS OBLIGATION is such that, if Principal shall
promptly make payment to all claimants as hereinafter defined, for all labor and material used or
reasonably required for use in the performance of the Contract, then this obligation shall be null
and void; otherwise it shall remain in full force and effect, subject, however, to the following
conditions:
1. A claimant is defined as one having a direct contract with the Principal or with a subcontractor
of the Principal for labor, material or both, used or reasonably required for use in the
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PYB-1
performance of the Contract, labor and material being construed to include that part of water,
gas, power, light, heat, oil, gasoline, telephone service or rental of equipment directly
applicable to the Contract.
2. The above named Principal and Surety hereby jointly and severally agree with the Owner that
every claimant as herein defined, who has not been paid in full before the expiration of a
period of ninety(90)days after the date on which the last of such claimant's work or labor was
done or performed, or materials were furnished by such claimant, may sue on this bond for
the use of such claimant, prosecute the suit to final judgment for such sum or sums as may
be justly due claimant, and have execution thereon. The Owner shall not be liable for the
payment of any costs or expenses of any such suit.
3. No suit or action shall be commenced hereunder by any claimant:
a. Unless claimant, other than one having a direct contract with the Principal, shall have
given written notice to any two of the following: the Principal, the Owner, or the Surety
above named, within ninety (90) days after such claimant did or performed the last of the
work or labor, or furnished the last of the materials for which such claimant is made, stating
with substantial accuracy the amount claimed and the name of the party to whom the
materials were furnished, or for when the work or labor was done or performed. Such
notice shall be served by mailing the same by registered mail or certified mail, postage
prepaid, in an envelope addressed to the Principal, Owner or Surety, at any place where
an office is regularly maintained for the transaction of business, or served in any manner
in which legal process may be served in the State in which the aforesaid project is located,
save that such service need not be made by a public officer.
b. After the expiration of one (1) year following the date on which Principal ceased work on
such Contract, it being understood, however, that if any limitation embodied in this bond
is prohibited by any law controlling the construction hereof such limitation shall be deemed
to be amended so as to be equal to the minimum period of limitation permitted by such
law.
c. Other than in a State Court of competent jurisdiction in and for the County or other political
subdivision of the State in which the Project, or any part thereof, is situated, or in the
United States District Court for the district in which the Project, or any part thereof, is
situated, and not elsewhere.
4. The amount of this bond shall be reduced by and to the extent of a payment or payments
made in good faith hereunder, inclusive of the payment by Surety of mechanics liens which
may be filed of record against such improvements, whether or not claim for the amount of
such lien be presented under and against this bond.
5. This bond is issued in compliance with Section 255.05, Florida Statutes, as may be amended.
A claimant, except a laborer,who is not in privity with the Contractor and who has not received
payment for its labor, materials, or supplies shall, within 45 days after beginning to furnish
labor, materials, or supplies for the prosecution of the work, furnish the Contractor with a
notice that he intends to look to the bond for protection. A claimant who is not in privity with
the Contractor and who has not received payment for its labor, materials, or supplies shall,
within 90 days after performance of the labor or after complete delivery of the materials or
supplies, deliver to the Contractor and to the Surety written notice of the performance of the
labor or delivery of the materials or supplies and the nonpayment. No action for the labor,
materials, or supplies may be instituted against the Contractor or the Surety unless both
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PYB-2
notices have been given. No action shall be instituted against the Contractor or the Surety on
the bond after one (1) year from the performance of the labor or completion of delivery of the
materials or supplies.
Signed and sealed this day of , 2021.
Principal (Seal)
Witness
Surety
Witness
Attorney-in-Fact
END OF PAYMENT BOND
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project PYB-3
TT YO
m I
�PTON 6
CITY OF BOYNTON BEACH
WARRANTY OF TITLE
STATE OF FLORIDA
COUNTY OF , being first duly sworn, deposes and says
as follows:
He is
of ,
(Title) (Name of Corporation or Firm)
a Florida Corporation ( ) Check One
a Florida General Partnership (____)
a Florida Limited Partnership (__.)
a Sole Proprietor (_)
which is named in Construction Contract dated the day of ,
20 , between such corporation as the CONTRACTOR and the City of Boynton Beach, Florida
as the OWNER, for the construction of
and Affiant is authorized to make this
Affidavit as, or on behalf of, the Contractor as named above.
Title to all work, materials and equipment covered by the attached Final Application for
Payment dated , passes to the Owner at the time of payment free and
clear of all liens, and all laborers, material men and subcontractors have been paid for performing or
furnishing the work, labor or materials upon such Contract work covered by the aforesaid Final
Application for Payment.
This statement under oath is given in compliance with Section 713.06 Florida Statutes.
Affiant
Sworn to and subscribed before me this
day of , 2021.
Notary Public, State of Florida at Large
My Commission expires:
(SEAL)
END OF WARRANTY OF TITLE
THIS FORM SHALL BE EXECUTED BY CONTRACTOR AND SUBMITTED
AT AWARD
Bid No.002-2511-21/RW—Harvey E.Oyer Jr.Park Marina Boat Ramp Improvement Project WT-1
City of Boynton Beach
Risk Management
INSURANCE ADVISORY FORM
Under the terms and conditions of all contracts,leases,and agreements,the City requires appropriate coverages listing the City of
Boynton Beach as Additional Insured. This is done by providing a Certificate of Insurance listing the City as"Certificate Holder"
and"The City of Boynton Beach is Additional Insured as respect to coverages noted."Insurance companies providing insurance
coverages must have a current rating by A.M. Best Co. of"B+" or higher. (NOTE: An insurance contract or binder may be
accepted as proof of insurance if Certificate is provided upon selection of vendor.) The following is a list of types of insurance
required of contractors,lessees,etc.,and the limits required by the City: (NOTE: This list is not all inclusive,and the City
reserves the right to require additional types of insurance,or to raise or lower the stated limits,based upon identified risk.)
TYPE (Occurrence Based Only) MINIMUM LIMITS REOUIRED
General Liability General Aggregate $ 1,000,000.00
Commercial General Liability Products-Comp/Op Agg. $ 1,000,000.00
Owners&Contractor's Protective(OCP) Personal&Adv.Injury $ 1,000,000.00
Liquor Liability Each Occurrence $ 1,000,000.00
Professional Liability Fire Damage(any one fire) $ 50,000.00
Employees&Officers Med.Expense(any one person) $ 5,000.00
Pollution Liability
Asbestos Abatement
Lead Abatement
Broad Form Vendors
Premises Operations
Underground Explosion&Collapse
Products Completed Operations
Contractual
Independent Contractors
Broad Form Property Damage
Fire Legal Liability
Automobile Liability Combined Single Limit $ 300,000.00
Any Auto Bodily Injury(per person) to be determined
All Owned Autos Bodily Injury(per accident) to be determined
Scheduled Autos Property Damage to be determined
Hired Autos Trailer Interchange $ 50,000.00
Non-Owned Autos
PIP Basic
Intermodal
Garage Liability Auto Only,Each Accident $ 1,000,000.00
Any Auto Other Than Auto Only $ 100,000.00
Garage Keepers Liability Each Accident $ 1,000,000.00
Aggregate $ 1,000,000.00
Excess Liability Each Occurrence to be determined
Umbrella Form Aggregate to be determined
Worker's Compensation Statutory Limits
Employer's Liability Each Accident $ 100,000.00
Disease,Policy Limit $ 500,000.00
Disease Each Employee $ 100,000.00
Property
Homeowners Revocable Permit $ 300,000.00
Builder's Risk Limits based on Project Cost
Other- As Risk Identified to be determined
INSURANCE ADVISORY